Terms & Conditions

Effective Date: November 20, 2025

1. Introduction

These Terms & Conditions govern the use of the website and professional services provided by MHS Technologies (Engineers & Contractors). By accessing our website or engaging our services, you agree to comply with these terms.

2. Services

MHS Technologies provides Civil, Electrical, Telecommunications, IT, and System Integration services. All services are delivered in accordance with:

• Agreed project scope and technical requirements
• Approved timelines and milestones
• Commercial terms and signed proposals or contracts

3. Use of Website

All content on this website is provided for general information and marketing purposes only. Unauthorized use, duplication, modification, or distribution of any content, text, images, or design elements is strictly prohibited.

We reserve the right to update or change website content, structure, or availability without prior notice.

4. Payments & Billing

All payments must be made according to the agreed schedule, invoice terms, or contract. Delayed or partial payments may result in:

• Project delays or rescheduling of activities
• Temporary suspension of services
• Late payment charges, if defined in the agreement

5. Limitation of Liability

MHS Technologies is not liable for any indirect, incidental, special, or consequential damages arising out of:

• The use or inability to use our website or services
• Delays caused by third-party vendors, utilities, or site conditions
• Incorrect or incomplete information provided by the client

Our total liability, if any, will be limited to the value of the specific service or contract under dispute.

6. Intellectual Property

All logos, brand assets, designs, documentation, drawings, reports, and deliverables created by MHS Technologies remain the intellectual property of MHS Technologies, unless otherwise stated in a written contract.

Clients are granted a limited right to use deliverables solely for the agreed project or business purpose.

7. Changes to Terms

MHS Technologies may update or modify these Terms & Conditions from time to time. Updated versions will be posted on this website, and continued use of our services will be treated as acceptance of the revised terms.

8. Governing Law

These Terms & Conditions are governed by the laws of Pakistan. Any disputes arising from or related to these terms will be subject to the exclusive jurisdiction of the courts of Karachi.

9. Contact

For any questions related to these Terms & Conditions, please contact:

Email: info@mhs-tech.com.pk